Council archive · source document
Appendix C - Current Development Approval · MCU25/0053.01
Original PDF page 1, section 1. The text section number identifies this passage in the reader.
Appendix C – Current Development Approval (MCU25/0053 and OPW25/0074) Other Change Application - 7 Noosa Parade 45
See the original
The page text is free to read. Viewing or downloading an original file needs an account.
Log in to see the originalFull text of sections 2 to 14 (of 28)
Section 2
Officer: Matthew Pinese
Direct Telephone: 07 53296316
Our Reference: MCU25/0053 OPW25/0074
Your Reference: P0041116
28 November 2025
Seymour Leisure P/L TTE
C/- Urbis Pty Ltd
Level 32, 300 George Street
BRISBANE 4000
[email protected] [email protected]
Dear Hannah,
Decision Notice
Planning Act 2016
I refer to your application and advise that on 21 November 2025, Council decided to approve the
application subject to conditions.
Details of the decision are as follows:
1. APPLICATION DETAILS
Application No: MCU25/0053 and OPW25/0074
Street address: 7 Noosa Parade, Noosa Heads Qld 4567
Real property description: BUP10936
Planning Scheme: Noosa Plan 2020 (25 September 2020)
2. DECISION DETAILS
Council decided to issue the following type of approval:
• Development Permit for Material Change of Use – Dwelling house (Basement)
• Development Permit for Operational Works – Excavation
3. CURRENCY PERIOD OF APPROVAL
The currency period for this development approval is stated in the conditions below.
4. ASSESSMENT MANAGER CONDITIONS
DEVELOPMENT PERMIT FOR MATERIAL CHANGE OF USE (MCU25/0053)
DWELLING HOUSE (BASEMENT)
PLANNING
When Conditions must be Complied With
1. Unless otherwise stated, all conditions of this Decision Notice must be complied with prior to
the use commencing, and then compliance maintained at all times while the use continues.
ABN 97.969.214.121 PO Box 141
noosa.qld.gov.au Tewantin QLD 4565
[email protected] 07 5329 6500
Page 1 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 3
Currency Period
2. This development approval lapses if the use has not happened by 21 November 2031,
unless an application to extend the currency period is approved by Council.
Approved Plans
3. Development authorised by this approval must be undertaken generally in accordance with
the Approved Plans listed in the table below.
Plan No. Rev. Plan/Document Name Date
24048 AR 10.01 4 Site Plan – Existing, Grid Setout and Proposed 22/09/2025
prepared by Bureau Proberts
24048 AR 21.01 10 G.A. Basement Plan prepared by Bureau Proberts 22/09/2025
24048 AR 21.02 9 G.A. Ground Floor Plan prepared by Bureau 22/09/2025
Proberts
24048 AR 21.03 8 G.A. First Floor Plan prepared by Bureau Proberts 22/09/2025
24048 AR 21.04 7 G.A. Roof Plan prepared by Bureau Proberts 22/09/2025
24048 AR 30.01 7 North and South Elevations prepared by Bureau 22/09/2025
Proberts
24048 AR 30.03 7 East and West Elevations prepared by Bureau 22/09/2025
Proberts
24048 AR 40.01 9 Sections 1 and 2 prepared by Bureau Proberts 22/09/2025
24048 AR 40.02 7 Sections 3 and 4 prepared by Bureau Proberts 22/09/2025
24048 AR 40.03 7 Sections 5 and 6 prepared by Bureau Proberts 22/09/2025
Car Parking
4. Car parking spaces must be provided on site as shown on the approved plans and made
available and accessible at all times for residents. Vehicle manoeuvring areas are provided
on site in accordance with the Australian Standards for Off-street car parking so vehicles
enter and leave the site in a forward gear.
Lighting Amenity
5. No flood lighting must be used on site. Any vertical illumination resulting from direct, reflected
or other incidental external lighting emanating from the site must not exceed 8 lux when
measured at any point 1.5 metres outside the boundary and at any level from ground level
upward.
Environment
6. Sediment or any other material including building materials or waste products must not be
deposited or released into the road reserve, stormwater drain or adjacent properties.
Landscaping Works
7. A minimum of 20% of the site must be retained as soft landscaping.
Side boundaries are to include a mix of vegetation which includes shrubs and trees. The
plants are to be sourced from the Noosa Plan 2020 - PSP2 Landscaping planning scheme
policy and maintained for the life of the use at the site.
Page 2 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 4
Existing vegetation in the road reserve must be retained, unless written authorisation from
Council is granted for the clearing.
Fencing
8. The maximum height any fences adjoining a residential use must not exceed 2.0m above
the natural ground level at any point. Unless is required to satisfy the acoustic condition of
this notice and accepted as generally in accordance by Council.
9. Street fencing must be provided generally as shown on the Approved Plans, and not exceed
1.8 metres in height along Noosa Parade
10. The area of land between the fence and the front property boundary must be landscaped to
screen the fence from the street. Landscaping must not encroach more than 500 millimetres
into the road reserve or within 1.5 metres of a sealed footpath.
Property Access and Driveways
11. Vehicle access to the subject site is limited to the constructed driveway only. A clause must
be included in the contract of sale for the subject site which requires vehicle access to be
from the constructed driveway only, and which prohibits the driveway from being relocated
without Council agreement.
12. Car parking spaces must be provided on site as shown on the approved plans and always
made available and accessible for residents. Vehicle manoeuvring areas are to be provided
on site in accordance with the Australian Standards for Off-street car parking so vehicles
enter and leave the site in a forward gear.
Stormwater Drainage
13. The site must be provided with a stormwater drainage system connecting to a lawful point of
discharge without causing scour or damage to the subject site or any adjoining properties.
Easements
14. Unless otherwise agreed in writing by the relevant service provider, any public or third party
infrastructure located on the subject site must be placed within an easement registered
against the title of the property.
15. All easements must be designed in accordance with the planning scheme and granted at no
cost to the Grantee. Where the Grantee is Council or a service authority, the easement
documentation must be in accordance with the Grantee’s standard easement terms. Draft
easement documentation must be submitted to Council for endorsement.
16. All works must be kept clear of any existing or proposed easements on the subject land,
unless agreed otherwise in writing by the Grantee.
Geotechnical Stability
17. All works must be carried out in accordance with the recommendations contained in PTG
Consulting’s Geotechnical Investigation Report (PTG/01608-0001, Rev. 0) dated 28
February 2025 and endorsed as part of the building approval.
18. A dilapidation survey must be carried out of all adjacent properties, structures and
infrastructure prior to the commencement of works and endorsed as part of the building
approval.
Acid Sulfate Soils
19. All works must be carried out in accordance with PTG Consulting’s Acid Sulfate Soil
Management Plan (PTG/01608-0002, Rev. 0) dated 11 April 2025 and endorsed as part of
the building approval.
Dewatering
20. All dewatering works must be carried out in accordance with ADG Consulting’s Dewatering
Management Plan (ADG1777.25, Rev. 0) dated 1 May 2025 and endorsed as part of the
building approval.
Page 3 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 5
Earthworks and Retaining Walls
21. All earthworks and associated batters/retaining structures, both above and below ground
level, both temporary and permanent, must be undertaken in accordance with the conditions
of this approval and contained entirely within the subject site unless written permission from
the respective landowner(s) is provided to Council.
22. All retaining walls must be designed and constructed in accordance with the planning scheme
and must be certified by an RPEQ where exceeding 1.0m in height.
Damage to Services and Assets
23. Any damage caused to existing services and assets as a result of the development works
must be repaired at no cost to the asset owner at the following times:
a. where the damage would cause a hazard to pedestrian or vehicle safety, immediately;
or
b. where otherwise, upon completion of the works associated with the development.
Any repair work which proposes to alter the alignment or level of existing services and assets
must first be referred to the relevant service authority for approval.
DEVELOPMENT PERMIT FOR OPERATIONAL WORKS (OPW25/0074)
(EARTHWORKS)
APPROVED PLANS
1. Development undertaken in accordance with this approval must generally comply with the
approved plans of development. The approved plans are listed in the following table unless
otherwise amended by these conditions.
Plan No. Rev. Plan/Document Name Date
0423 – OW3.1 B Bulk Earthworks Plan prepared by SCG 1/05/2025
Consulting
As annotated by Council
0423 – OW3.2 B Earthworks Sections prepared by SCG 1/05/2025
Consulting
As annotated by Council
0423 – OW3.3 A Earthworks Sections prepared by SCG 1/05/2025
Consulting
As annotated by Council
CURRENCY PERIOD
2. The Currency Period for this development approval lapses if the development has not
substantially started by 21 November 2027, unless an application to extend the currency
period is approved by Council.
PRIOR TO COMMENCEMENT OF WORKS
Engineering
3. All necessary approvals from external service providers (e.g., Unitywater) and external
parties on which the development works are proposed have been obtained and a copy
supplied to Council.
Page 4 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 6
4. A condition report including photographs of the frontage of the site must be completed prior
to any works commencing.
5. Any changes to the details associated with the supervising RPEQ or Principal Contractor
during construction, must be notified to council in writing within five business days of the
change occurring.
6. Any conflict between the development and an existing or proposed service must be referred
to the relevant service authority for determination prior to commencement of works.
DURING CONSTRUCTION
Engineering
7. The developer must meet any costs to repair damage to any Council asset during
construction, where damage is a result of the development works. Damage to assets must
be repaired immediately where it creates a hazard to the community. In circumstances where
the damage does not create a hazard to the community, it must be repaired immediately on
completion of the works associated with the development.
8. All works must be supervised by a Registered Professional Engineer of Queensland (RPEQ)
who is independent of the Developer and Principal Contractor, and they must certify that all
works conform to the Operational Works permit. Where municipal works are involved, such
confirmation must be submitted for the respective hold points prior to any site inspection by
Council Officers.
9. All works must be constructed and work procedure undertaken in accordance with:
a. The approved plans/documents and conditions detailed in this Decision Notice;
b. All relevant Noosa Council Planning Scheme Policies, standard drawings, standard
specifications and guidelines; and
c. The latest version of the Healthy Waterways document “Water Sensitive Urban Design
Technical Design Guidelines for South East Queensland” for all water quality devices
to be constructed on site.
Works within Road Reserve/Reinstatement
10. Safe pedestrian and vehicle access on all streets in the vicinity of the development must be
maintained at all times. Should footpath/road closures be necessary to carry out construction
works, Council’s Engineering Officer must be notified prior to the proposed closure and all
requirements complied with.
11. All frontage works must match neatly with existing road and verge/footpath features.
Additional works beyond the frontage may be required to provide an acceptable transition to
existing road and verge/footpath profiles.
12. Electrical conduits or other services proposed to be installed within existing and proposed
road reserves under existing sealed carriageways, concrete pathways, concrete/sealed
driveways or significant vegetation must be installed by boring. Trenching is not permitted,
unless specifically approved by Council.
Earthworks and Retaining Walls
13. All earthworks shall be undertaken in accordance with the provisions of AS 3798 Guidelines
on Earthworks for Commercial and Residential Development.
14. All earthworks and associated batters/retaining structures, both above and below ground
level, both temporary and permanent, must be contained entirely within the subject site
unless written permission from the respective landowner(s) is provided to Council. The
retaining systems shown on the engineering drawings do not form part of this approval.
15. Fall protection must be provided to retaining walls that are over 1m high.
16. Slope and batters are a maximum grade of:
a. 1 in 6 where in proximity to waterbodies;
Page 5 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 7
b. 1 in 4 for grassed areas;
c. 1 in 3 for planted areas; and
d. 1 in 2 for combined structural engineering and planting solutions.
Stormwater Drainage
17. Appropriate scour protection must be provided at the outlet of all stormwater pipes including
temporary outlets.
18. Works associated with this permit must not adversely impact on the existing drainage
conditions on other properties (e.g., by blocking or interfering with natural overland flows).
19. Construction of all internal stormwater drainage works must comply with the relevant
section/s of Australian Standard AS/NZS 3500.3.
Erosion and Sediment Control
20. Prescribed Water Contaminants (as defined in Schedule 10 of Environmental Protection
Regulation 2019) must not be released from the site or to waters within the site, or be likely
to be released should rainfall occur, unless all reasonable and practicable measures are
taken to prevent or minimise the release and concentration of contamination.
21. Sediment and erosion control measures must be in place prior to works commencing. If such
measures are not in place or are not satisfactory, “on the spot” fines may be issued. Such
fines can be issued if sediments from the site are found to enter or have the potential to enter
Council’s stormwater system, natural waterways, any downstream stormwater filtration
system or adversely impacting on other properties. The sediment and erosion control design
and measures have NOT been approved, it is the site's Supervising Engineer who is
responsible for ensuring that the sediment and erosion control measures have:
a. Been duly designed by an RPEQ or CPESC and constructed in accordance with "best
practise" methods,
b. Been revised by an RPEQ or CPESC to address the issues raised by changes in the
projected construction schedule and/or methods,
c. Been revised to address predicted rainfall events, and
d. Achieve the desired environmental outcomes.
Council may request further controls to be installed should the implemented measures be
found inefficient.
22. The erosion and sediment control measures must be designed, installed and maintained in
accordance with the supervising engineer instructions and the current best practice
standards.
(*) Refer to Advisory Note.
23. The developer must ensure non-essential exposure of soil is prevented by restricting the
extent of disturbance and minimising the duration of soil exposure to adverse weather
conditions and effectively turf, cover or stabilise any disturbed area without delay and prior
to rainfall occurring.
24. The developer must ensure sediment does not leave the site or enter onto adjoining
properties or Council’s drainage system due to surface runoff or on tyres of vehicles and/or
machinery. It is essential to implement appropriate approved erosion and sediment control
measures throughout the site during all phases of construction including vehicle shakedown
pad/grid (or similar) at the access to the construction site. Where sediments or other
contaminants are deposited on a road, they must be removed so as not to enter Council’s
drainage system or waterways.
25. Prior to the completion of the development and commencement of use, all site surfaces must
be effectively stabilised using methods which have achieved effective short-term stabilisation
and which will continue to achieve effective stabilisation in the medium to long-term.
Page 6 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 8
For the purpose of this condition, an effectively stabilised surface is defined as one that does
not, or is not likely to result in visible evidence of soil loss caused by sheet, rill or gully erosion
or lead to sedimentation, or lead to water contamination.
Damage to Services and Assets
26. Any damage caused to existing services and assets as a result of the development works
must be repaired at no cost to the asset owner at the following times:
a. where the damage would cause a hazard to pedestrian or vehicle safety, immediately;
or
b. where otherwise, upon completion of the works associated with the development.
Any repair work which proposes to alter the alignment or level of existing services and assets
must first be referred to the relevant service authority for approval.
5. REFERENCE DOCUMENTS
Plan No. Rev. Plan/Document Name Date
PTG/01608 – O Geotechnical Investigation Report prepared by 28/02/2025
0001 PTG Consulting
PTG/01608 – 1 Acid Sulfate Soil Investigation Management Plan 11/04/2025
0002 prepared by PTG Consulting
ADG1777.25 O Dewatering Management Plan prepared by ADG 1/05/2025
Consulting
6. REFERRAL AGENCIES
Not applicable.
7. ADVISORY NOTES
The following notes are included for guidance and information purposes only and do not form part
of the assessment manager conditions:
1. An applicant for a development application may make an agreement with an assessment
manager, referral agency or other person to establish the responsibilities, or secure the
performance, of a party to the agreement about a development condition.
Building and Construction Industry (Portable Long Service Leave) Levy
2. The QLeave levy must be paid prior to the issue of a development permit where it is required.
Council will not be able to issue a Decision Notice without receipt of details that the Levy has
been paid.
General Advisory Notes
3. Council has undertaken an audit check of the Operational Works drawings in relations to the
proposed works. A detailed check of the calculations and drawings has not been undertaken,
as they have been certified by a RPEQ. The RPEQ bears full responsibility for all aspects of
the engineering design. Council reserves the right to require further amendments and/or
additions at a later date should design errors become apparent.
4. Should any changes or modifications to the approved plans be required as a result of
construction constraints, a “Request to change an existing approval” under the Planning Act
2016 must be made. Amended plans clearly indicating the changes must be lodged with this
application along with the appropriate fees.
Page 7 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 9
Environmental Advisory Notes
5. The Environmental Protection Act 1994 states that a person must not carry out any activity
that causes, or is likely to cause, environmental harm unless the person takes all reasonable
and practicable measures to prevent or minimise the harm. Environmental harm includes
environmental nuisance. In this regard persons and entities, involved in the civil, earthworks,
construction and landscaping phases of this development are to adhere to their ‘general
environmental duty’ to minimise the risk of causing environmental harm.
Erosion and Sediment Control
6. Accepted best practice standards include International Erosion Control Association
Australasia Best Practice Erosion and Sediment Control.
7. Qualified Person, for the purpose of erosion and sediment control is a Certified Professional
in Erosion and Sediment Control (CPESC) or suitably experienced Registered Professional
Engineer of Queensland (RPEQ).
8. As a general rule, a site is determined to have achieved effective short-term stabilisation if
at the time of the plan sealing inspection:
a. Methods of stabilisation are:
• appropriate for slopes and slope lengths; and
• are consistent with best practice environmental management practices such as in
the Manual for Erosion and Sediment Control or the IECA Manual; and
b. Stormwater runoff from the site is not currently and is not likely to result in visible
evidence of sedimentation or erosion, or lead to water contamination.
Road Reserve Permit
9. This development permit provides the applicant with written authority to undertake the
development in accordance with the conditions. Any additional activities that are undertaken
inside Council’s Road reserve for the purpose of acting on this development permit may
require a Road Reserve Permit. These additional activities may include, but are not limited
to, hoarding, pedestrian diversions, laneway closures, etc. To apply for a Road Reserve
Permit, or for more information, Contact Council’s Road Reserve Officer at
[email protected] Act 2014 – Fire Ant Control
10. Developers must remain vigilant for the presence of fire ants. Under the Biosecurity Act 2014,
individuals and businesses are responsible for ensuring that they follow the movement
controls for specific organic materials to help prevent the spread of fire ants within South
East Queensland’s fire ant biosecurity zones. Movement of a fire ant carrier from within a fire
ant biosecurity zone may need a biosecurity instrument permit. More information is available
on https://www.fireants.org.au/treat/business-andindustry/movement-controls.
8. PROPERTY NOTES
Not applicable.
9. VARIATION APPROVAL DETAILS
Not applicable.
10. FURTHER DEVELOPMENT PERMITS REQUIRED
Development Permit for Building Works All building work.
11. SUBMISSIONS
Not applicable.
Page 8 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 10
12. RIGHTS OF APPEAL
You are entitled to appeal against this decision. A copy of the relevant appeal provisions from the
Planning Act 2016 is attached.
During the appeal period, you as the applicant may suspend your appeal period and make written
representations to Council about the conditions contained within the development approval. If
Council agrees or agrees in part with the representations, a negotiated decision notice will be
issued. Only one negotiated decision notice may be given.
13. OTHER DETAILS
If you wish to obtain more information about the decision, electronic copies are available online at
www.noosa.qld.gov.au or at Council Offices.
Yours faithfully
Matthew Pinese
Development Planner | Development Assessment
Development & Regulation
Enc: Appeal Rights
Approved Plans/Documents
Page 9 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 11
Appeal Rights
PLANNING ACT 2016 & PLANNING REGULATION 2017
Chapter 6 Dispute resolution (3) The appellant or, for an appeal to a tribunal, the registrar must,
within the service period, give a copy of the notice of appeal to –
Part 1 Appeal rights
(a) the respondent for the appeal; and
229 Appeals to tribunal or P&E Court
(b) each co-respondent for the appeal; and
(1) Schedule 1 of the Planning Act 2016 states –
(c) for an appeal about a development application under schedule
(a) Matters that may be appealed to –
1, table 1, item 1 – each principal submitter for the
(i) either a tribunal or the P&E Court; or development application; and
(ii) only a tribunal; or (d) for and appeal about a change application under schedule 1,
table 1, item 2 – each principal submitter for the change
(iii) only the P&E Court; and
application; and
(b) The person-
(e) each person who may elect to become a co-respondent for the
(i) who may appeal a matter (the appellant); and appeal, other than an eligible submitter who is not a principal
submitter in an appeal under paragraph (c) or (d); and
(ii) who is a respondent in an appeal of the matter; and
(f) for an appeal to the P&E Court – the chief executive; and
(iii) who is a co-respondent in an appeal of the matter; and
(g) for an appeal to a tribunal under another Act – any other
(iv) who may elect to be a co-respondent in an appeal of the
person who the registrar considers appropriate.
matter.
(4) The service period is –
(2) An appellant may start an appeal within the appeal period.
(a) if a submitter or advice agency started the appeal in the P&E
(3) The appeal period is –
Court – 2 business days after the appeal has started; or
(a) for an appeal by a building advisory agency – 10 business
(b) otherwise – 10 business days after the appeal is started.
days after a decision notice for the decision is given to the
agency; or (5) A notice of appeal given to a person who may elect to be a co-
respondent must state the effect of subsection (6).
(b) for an appeal against a deemed refusal – at any time after the
deemed refusal happens; or (6) A person elects to be a co-respondent by filing a notice of election,
in the approved form, within 10 business days after the notice of
(c) for an appeal against a decision of the Minister, under chapter
appeal is given to the person.
7, part 4, to register premises or to renew the registration of
premises – 20 business days after a notice us published under 231 Other appeals
section 269(3)(a) or (4); or
(1) Subject to this chapter, schedule 1 and the P&E Court Act, unless
(d) for an appeal against an infrastructure charges notice – 20 the Supreme Court decides a decision or other matter under this
business days after the infrastructure charges notice is given Act is affected by jurisdictional error, the decision or matter is non-
to the person; or appealable.
(e) for an appeal about a deemed approval of a development (2) The Judicial Review Act 1991, part 5 applies to the decision or
application for which a decision notice has not been given – matter to the extent it is affected by jurisdictional error.
30 business days after the applicant gives the deemed
(3) A person who, but for subsection (1) could have made an
approval notice to the assessment manager; or
application under the Judicial Review Act 1991 in relation to the
(f) for any other appeal – 20 business days after a notice of the decision or matter, may apply under part 4 of that Act for a
decision for the matter, including an enforcement notice, is statement of reasons in relation to the decision or matter.
given to the person.
(4) In this section –
Note – decision includes-
See the P&E Court Act for the court’s power to extend the appeal
(a) conduct engaged in for the purpose of making a decision; and
period.
(b) other conduct that relates to the making of a decision; and
(4) Each respondent and co-respondent for an appeal may be heard
in the appeal. (c) the making of a decision or failure to make a decision; and
(5) If an appeal is only about a referral agency’s response, the (d) a purported decision; and
assessment manager may apply to the tribunal or P&E Court to
(e) a deemed refusal.
withdraw from the appeal.
non-appealable, for a decision or matter, means the decision or
(6) To remove any doubt. It is declared that an appeal against an
matter-
infrastructure charges notice must not be about-
(a) is final and conclusive; and
(a) the adopted charge itself; or
(b) may not be challenged, appealed against, reviewed, quashed,
(b) for a decision about an offset or refund-
set aside or called into question in any other way under the
(i) the establishment cost of trunk infrastructure identified in Judicial Review Act 1991 or otherwise, whether by the
a LGIP; or Supreme Court, another court, a tribunal or another entity; and
(ii) the cost of infrastructure decided using the method (c) is not subject to any declaratory, injunctive or other order of
included in the local government’s charges resolution. the Supreme Court, another court, a tribunal or another entity
on any ground.
230 Notice of appeal
232 Rules of the P&E Court
(1) An appellant starts an appeal by lodging, with the registrar of the
tribunal or P&E Court, a notice of appeal that- (1) A person who is appealing to the P&E Court must comply with the
rules of the court that apply to the appeal.
(a) is in the approved form; and
(b) succinctly states the grounds of the appeal. (2) However, the P&E Court may hear and decide an appeal even if
the person has not complied with the rules of the P&E Court
(2) The notice of appeal must be accompanied by the required fee.
Page 10 of 10
Document Set ID: 24343665
Version: 2, Version Date: 28/11/2025
Section 12
6
2.2
GENERAL NOTES
1
es 43
VERIFY ALL DIMENSIONS AND LEVELS BEFORE COMMENCING WORK. DO NOT SCALE FROM DRAWING.
1
)
ve
(R 218
er
N
5
2.0
COPYRIGHT
3
2.2
NOOSA COUNCIL THE COPYRIGHT OF THESE DOCUMENTS AND ALL WORKS EXECUTED FROM THESE DOCUMENTS
SHALL REMAIN THE PROPERTY OF THE ARCHITECT OR ON CREATION VEST IN THE ARCHITECT.
4
2.0
THESE DOCUMENTS MAY ONLY BE USED TO PRODUCE THE PROJECT FOR THE CLIENT AND IN THE
APPROVED PLAN LOCATION DESCRIBE HEREON
PARK
ce
MCU25/0053 & OPW25/0074
en
fF
6
2.26
IT
To 07
2.2
po
EP
3.
L
TE
21 NOVEMBER 2025
2
6
2.0
4 MCU RFI RESPONSE 22.09.25
1.4
8
2
4
8
9
55.457 m
2.1
2.3
5
2.3
1.8
2.2
2.3
3 CONSULTANT ISSUE 02.05.25
9
1.1
142° 02' 10"
1
REMOVE FENCE REMOVE FENCE 2 CONSULTANT ISSUE 30.04.25
2.0
6
6
all
3
2.6
2.6
2.6
5
fW
2.6
1
2
3
2.6
2.6
2.6
3
1
To 08
2.6
2.6
po
7
4
1 UPDATED BASEMENT, STRUCTURE 11.03.25
2.6
2.4
4.
1
te .59
2.4
5
ut 2
9
2.6
r
0
2.1
2
2.6
all 1
4
3
2.3
f W 3.9
2.6
2.6
2
fG
2.3
M
1
2.6
4
To 91
po
5
W
5
3
2.3
REV DESCRIPTION DATE
2.3
1.7
4.
2.3
po
3
3
8
2.3
2.6
1.1
T2 o
2
2.6
2.6
2
REMOVE POOL REVISION SCHEDULE
2.6
ut .92
4
FH
2
fG 4
r
2.6
1.6
te
0
1.8
4
NOOSA PARADE
2.6
6
9
3
2.6
1.7
2.6
3
5
po
2.6
2.6
NOOSA INLET
To
0
9
2
2.0
2.1
2.6
6
2.6
3
5
5
2
2.6
2.6
2.6
2.1
5
0
6
2.6
3
2.3
2.6
2.2
5
5
7
5
2.6
2.6
2.6
2.6
RETAIN JETTY AND LANDING
1
4
2.1
REMOVE CONCRETE ENTRY PATH AND
2.6
3
53° 28' 00"
1.7
9
20.123 m
1.7
L
4
8
VE
1.7
LANDSCAPING LOCATED ON VERGE AS
1.1
1 3 .16
LE
2
Ap .32
Ap 73
R
FL 49
ex
ex
REQUIRED TO SUIT NEW WORKS
OO
6.
REMOVE BUILDING REMOVE BUILDING
2.
Ap .38
Ap .75
2
ex
1.8
ex
13
6
7
1.1
REMOVE ALL STRUCTURE AND
1
4
6
1.8
2
2.1
2.2
2.1
9
1
2.1
1.7
9
2.0
LANDSCAPING FROM THE SITE
0
VE 0
2.3
1
LE 2.5
2.5
1.9 00
4
UNLESS NOTED Section 13
OTHERWISE
L
2.2
2.
0
7
RECTIFY ALL DAMAGE TO KERB,
2
2.1
1.8
t
4
os
R
2.1
8
OO
2.1
lP
CROSSOVER, FOOTPATH AND
8
9
FL
2.1
2.3
ee
EXCAVATE TO LEVELS AS RETAIN REVETMENT WALL
ND
St
LANDSCAPING IN ACCORDANCE WITH
OU
7
2.4
2
232° 02' 10"
REQUIRED BY NEW WORKS
GR
2.1
1.8 .19
20.115 m
LOCAL AUTHORITY REQUIREMENTS
2
3
REFER TO CIVIL DRAWINGS
ut 1.57
AT .99
r
1
te
2.42.24
E
7
1
2.112
VE 0
2
1
3
2.0
3
LE 5.4
2.1
1
2.1
2.
0
0 2.3
2.3
ut 4.81
5
ut 4.91
fG
L
ut 4.88
1.8
GR
ut 4.81
VE .40
r
TE
TE
r
AT 6
te
po
r
te
GR 2.3
TE
SW
FL ter
te
7
A
A
5
E
2.2
L
E 1
REMOVE DRIVEWAY
1.1
VE .30
GR
3
To
A
GR
SW 25
SW 10
R
LE 8.
fG
fG
GR
SW 09
0
OO
8
fG
LE 2.5 L
2.
2.
L
2
LE
fG
2.2
1.7
po
2.
po
V
VE 0
po
8
R
po
S8W
LE
2.1
To
OO
To
ND
To
RETAIN CROSSOVER
2.2
L
To
R
R
FL
CO
OO
OO
ST
SE
FL
FL
FIR
R
ST
ND
OO
FIR
CO
9
FL
6
2.1
2.2
SE
ND
OU
REMOVE TREES
all
4
2
2.1
3
7
3
GR
2.2
8
1
fW
2.1
2.0
1.9
2.1
2.1
SW GRATE
To 05
po
REMOVE FENCE
4.
55.947 m
1
3
6
2.3
4
1
2.3 .24
2.2
1.8
5
2.3
2.2
2.1
1.89
1
M
7
er 2.5
2
W
3
322° 02' 10"
9
1
2.0
OL 7
1.1
1.9
r
NH 1.6
E
RETAIN FENCE
te
9
9
tt
ut
1.6
1
2.1
2.1
Gu
RECTIFY ALL DAMAGE
fG
all 7
0
MA
6
f W 4.0
To 26
of
en .24
2.0
po
5
2.0
2
6
7.2
2.2
7.
3
2.1
Pa 99 Top
ce
R
3
TO ADJOINING FENCE
2.1
l
SE 5
WE
ve
1.8
4
Section 14
Le
po
9.9
1
fF
0
2.0
2.0
S
NA .22
tio
To
po
4.
IL
2
To
Le 4.99
oo 0
f D 4.6
oo 0
l
r
ve
f D 4.6
PARK
r
ADJOINING
tio
po
Pa
po
To
BUILDING
8
2
To
2.1
2.2
0
CP
04
2.0
P4
SITE PLAN - EXISTING
GT
1
4
7
2.1
1 : 200
2.1
es 43
N 2
)
ve
(R 218
er
1 2 3 4 5 6 7
7292 3380 8500 7160 11435 6000 4690 7000
55.457 m
142° 02' 10"
2005
A A
NOOSA PARADE
NOOSA INLET
11210
53° 28' 00"
20.123 m
232° 02' 10"
20.115 m
B B
4400
C C
2500
55.947 m
322° 02' 10"
1 2 3 4 5 6 7
GRID SETOUT PLAN
3 1 : 200
1 2 3 4 5 6 7
55.457 m
142° 02' 10"
COURTYARD
A A
POOL
bureau^proberts PTY LTD
ABN 53 073 087 993 ACN 073 087 993
LEVEL 14, 100 CREEK STREET, BRISBANE QLD 4000, GPO Box 3204 QLD 4001
P: 07 3221 0672 F: 07 3221 0683 EMAIL : [email protected] www.bureauproberts.com.au
NOOSA PARADE
NOOSA INLET
CLIENT:
SEYMOUR GROUP
PROJECT:
COURTYARD POOL TERRACE
EXISTING JETTY & PONTOON NOOSA RESIDENCE
53° 28' 00"
20.123 m
232° 02' 10"
ADDRESS:
20.115 m
ROOF
REAR TERRACE 7 NOOSA PARADE
ROOFLIGHTS
B B DRAWN BY: NORTH:
TH
CHECK BY:
DRY COURT JC
DRIVEWAY
PROJECT
ARCHITECT JC
C C DESIGN
ARCHITECT AB
COURT DRY COURT
SCALE:
55.947 m
322° 02' 10" 5 1 : 200 [A1]
DRAWING TITLE:
SITE PLAN - EXISTING, GRID SETOUT &
PROPOSED
1 2 3 4 5 6 7 CAD FILE REF: DATE:
C:\_Revit Local\24048_7 Noosa Parade_B.A_larissaf4R2ZR.rvt
22.09.25
PROJECT NO: PHASE: DRAWING NUMBER: REVISION:
SITE PLAN - PROPOSED 24048 B.A. AR 10.01 4
2 1 : 200 22/09/2025 3:36:54 PM
Document Set ID: 24343720
24149760
Version: 1, Version Date: 28/11/2025
26/09/2025
The text continues on section 15.
Used in these records
Appendix C - Current Development Approval.pdfRelated documentApplication case desk ↗
About this file
- File size
- 5.9 MB (large file)
- File type
No other editions are linked here.
Original file
Log in to download the original file
The download may take up to a minute.